Can the Contractor ask for an extension of time?

Yes, there are certain instances when the Contractor shall be entitled to an equitable adjustment of Completion Time. For example, the Contractor shall be entitled to an extension of time when the Contractor is obstructed or delayed in the completion of the Work by:

 

 a)    the act, neglect, delay or fault of the Owner, or any other contractor employed by the Owner on the Work;

 b)    third-party strikes or lockouts or strikes by employees other than the Contractor's employees or a lockout by an employer other than the Contractor;

 c)    an act of God or force majeure;

 d)    unsuitable weather conditions which render the work impracticable or impossible or which slow down the prosecution of the Work;

 e)    peace and order conditions;

 f)     changes ordered or authorized by the Owner or authorized under the Contract; and

 g)    delay authorized by the Owner pending arbitration of an unresolved dispute between the Owner and the Contractor.

 

For delay caused by b), c), d), e) and f), the Contractor shall, within fifteen (15) days from the occurrence of the event which caused the delay, notify the Owner and the Owner shall, not later than fifteen (15) days from receipt of such notice, give the Contractor an equitable adjustment of the Completion Time. The failure of the Owner to reply to the Contractor or to give an equitable adjustment of the Completion Time shall be deemed an approval by the Owner of the adjustment requested by the Contractor.

 

For delay caused by a) and g), and in default of an agreement between the Owner and the Contractor, the Contractor shall be entitled to an adjustment of Completion Time equal to the delay caused by such factors. However, the Contractor shall not be entitled to extension of Completion Time due to the alleged failure of the Owner to furnish materials or information or provide drawings, unless in the construction schedule approved by the Owner, they are necessary to prosecute the Work in the order required, and the failure of the Owner to provide them caused a delay in the work of the Contractor.

 

The Owner, taking into account the construction schedule approved by him and the progress of the work of the Contractor, is conclusively presumed to know when materials, equipment or supplies or drawings to be provided by the Owner shall be required by the Contractor, and the failure of the Contractor to give prior or timely notice to the Owner of the date when such material, equipment or supplies or drawings shall be required shall not be a ground for denying the Contractor an adjustment of Completion Time.

The failure of the Owner to reply to the Contractor's request for adjustment of Completion Time within fifteen (15) days from the date of receipt of the request shall be deemed an approval by the Owner of the adjustment requested by the Contractor. Such request shall be deemed a formality which does not affect the right of the Contractor to an equitable adjustment of Completion Time as provided.

Delay in the payment of any progress billing as required in Article 22.05 shall automatically extend the Completion Time by a period equal to the delay. The Contractor shall not be required to give notice to the Owner nor be required to establish that such delay actually delayed the prosecution of the Work or delayed the Contractor to a period equal to the delay in the payment of the billing.