- Transparency Seal
- Contractor's Licensing and Registration
- Overseas Contractors Registration
- Constructors Performance Evaluators Accreditation
- Construction Arbitration/Mediation
- Contact Us
Can the Owner make use of completed portions of the Work?
Yes, the Owner may take possession of and use any completed or partially completed portion of the Work, although the time for completing it or portions thereof may not have expired; but such taking of possession and use shall not be deemed an acceptance of any work not completed in accordance with the Contract. Neither shall it be deemed a waiver by the Owner of the right to claim damages due to delay in the completion of the Work. If such prior use increases the Contractor’s cost or delays the completion of uncompleted work or causes refinishing of completed work, the Contractor shall be entitled to extra compensation or extension of time or both.
However, if the Owner does take over any portion prior to overall completion, he or she shall issue a Certificate of Completion for such portion taken over and release retention as required by the Contract.